2024 Minnesota Statutes

CHAPTER 103E. DRAINAGE

Table of Sections

Section	Headnote
GENERAL PROVISIONS
103E.005	DEFINITIONS.
103E.011	DRAINAGE AUTHORITY POWERS.
103E.015	CONSIDERATIONS BEFORE DRAINAGE WORK IS DONE.
103E.021	PLANTING DITCHES WITH PERENNIAL VEGETATION.
103E.025	PROCEDURE FOR DRAINAGE PROJECT THAT AFFECTS STATE LAND OR WATER AREA USED FOR CONSERVATION.
103E.031	CONNECTION WITH DRAINS IN ADJOINING STATES.
103E.035	DEFECTIVE NOTICE.
103E.041	PERSONAL SERVICE IN LIEU OF OTHER METHODS OF NOTICE.
103E.043	INFORMAL MEETINGS.
103E.045	FAILURE TO ATTEND HEARINGS; DRAINAGE AUTHORITY.
103E.051	DEFECTIVE PROCEEDINGS.
103E.055	REIMBURSING COST OF FORMER SURVEYS WHEN USED LATER.
103E.061	RIGHT OF ENTRY.
103E.065	DRAINAGE INSPECTORS.
103E.067	DITCH BUFFER STRIP; ANNUAL REPORTING.
103E.071	COUNTY ATTORNEY.
103E.075	OBSTRUCTING DRAINAGE SYSTEM.
103E.081	CRIMES RELATED TO DRAINAGE SYSTEMS; PENALTIES.
103E.085	ENFORCEMENT.
103E.091	APPEALS.
103E.095	APPEAL FROM ORDERS DISMISSING OR ESTABLISHING DRAINAGE SYSTEMS.
103E.097	ATTORNEY FEES ON APPEAL.
103E.101	DRAINAGE PROCEEDING AND CONSTRUCTION RECORDS.
103E.105	ADVICE ABOUT DRAINAGE QUESTIONS.
103E.111	FIELD SURVEYS AND INVESTIGATIONS BY DIRECTOR.
103E.115	HYDROLOGICAL AND DRAINAGE INFORMATION.
103E.121	DRAIN TILE; MANUFACTURING STUDIES.
PETITIONS FOR DRAINAGE PROJECTS
103E.202	PETITIONS.
103E.212	NEW DRAINAGE SYSTEM PROJECTS.
103E.215	IMPROVING DRAINAGE SYSTEMS.
103E.221	IMPROVING OUTLETS.
103E.225	LATERALS.
103E.227	IMPOUNDING, REROUTING, AND DIVERTING DRAINAGE SYSTEM WATERS.
103E.231	DISMISSING OR DELAYING PROCEEDINGS; PETITIONERS.
103E.235	DRAINAGE SYSTEM IN TWO OR MORE COUNTIES.
103E.238	COUNTY ATTORNEY REVIEW OF PETITION AND BOND.
PRELIMINARY SURVEY AND HEARING
103E.241	ENGINEER.
103E.245	PRELIMINARY SURVEY AND PRELIMINARY SURVEY REPORT.
103E.251	FILING PRELIMINARY SURVEY REPORT.
103E.255	COMMISSIONER'S PRELIMINARY ADVISORY REPORT.
103E.261	PRELIMINARY HEARING.
DETAILED SURVEY AND VIEWING
103E.265	ORDER FOR DETAILED SURVEY AND SURVEY REPORT.
103E.271	DETAILED SURVEY.
103E.275	ENGINEER'S VARIANCE FROM DRAINAGE AUTHORITY ORDER.
103E.281	SOIL SURVEY.
103E.285	DETAILED SURVEY REPORT.
103E.291	FILING DETAILED SURVEY REPORT.
103E.295	REVISING ENGINEER'S DETAILED SURVEY REPORT AFTER ACCEPTANCE.
103E.301	COMMISSIONER'S FINAL ADVISORY REPORT.
103E.305	VIEWERS' APPOINTMENT AND QUALIFICATION.
103E.311	VIEWER DUTIES.
103E.315	ASSESSING DRAINAGE BENEFITS AND DAMAGES.
103E.321	VIEWERS' REPORT.
103E.323	PROPERTY OWNERS' REPORT.
FINAL HEARING
103E.325	FINAL HEARING NOTICE.
103E.331	JURISDICTION OF PROPERTY BY DRAINAGE AUTHORITY.
103E.335	PROCEEDINGS AT FINAL HEARING.
103E.341	DRAINAGE AUTHORITY FINAL ORDER.
103E.345	APPORTIONING COST FOR JOINT COUNTY DRAINAGE SYSTEMS.
REDETERMINING BENEFITS
103E.351	REDETERMINING BENEFITS AND DAMAGES.
OUTLETS FOR DRAINAGE SYSTEMS
103E.401	USE OF DRAINAGE SYSTEM AS OUTLET.
103E.405	OUTLETS IN ADJOINING STATES.
103E.411	DRAINAGE SYSTEM AS OUTLET FOR MUNICIPALITY.
CONSTRUCTING DRAINAGE PROJECT
103E.501	CONTRACT AND BOND.
103E.505	AWARDING CONSTRUCTION CONTRACT.
103E.511	CONTRACT NOT AWARDED; EXCESSIVE BIDS OR COSTS.
103E.515	DAMAGES; PAYMENT.
103E.521	CONSTRUCTION SUPERVISION.
103E.525	CONSTRUCTING AND MAINTAINING BRIDGES AND CULVERTS.
103E.526	CONSTRUCTING ROAD INSTEAD OF BRIDGE OR CULVERT.
103E.53	RULES TO STANDARDIZE FORMS.
103E.531	INSPECTING DRAINAGE CONSTRUCTION; PARTIAL PAYMENTS.
103E.535	PARTIAL PAYMENT OF RETAINED CONTRACT AMOUNTS.
103E.541	EXTENDING TIME ON CONTRACTS.
103E.545	REDUCING CONTRACTOR'S BOND.
103E.551	CONTRACTOR DEFAULT.
103E.555	ACCEPTING CONTRACT.
FUNDING, COLLECTING, AND PAYING DRAINAGE SYSTEM COSTS
103E.601	DRAINAGE LIEN STATEMENT.
103E.605	EFFECT OF FILED DRAINAGE LIEN.
103E.611	PAYING DRAINAGE LIENS AND INTEREST.
103E.615	ENFORCING ASSESSMENTS.
103E.621	SATISFYING LIENS.
103E.625	SUBDIVISION BY PLATTING; LIENS APPORTIONED.
103E.631	APPORTIONING LIENS.
103E.635	DRAINAGE BOND ISSUES.
103E.641	DRAINAGE FUNDING BONDS.
103E.645	ALLOWANCE AND PAYMENT OF FEES AND EXPENSES.
103E.651	DRAINAGE SYSTEM ACCOUNT.
103E.655	PAYING DRAINAGE SYSTEM COSTS.
103E.661	EXAMINING AND ESTABLISHING DRAINAGE SYSTEM ACCOUNTS; STATE AUDITOR.
PROCEDURE TO REPAIR DRAINAGE SYSTEMS
103E.701	REPAIRS.
103E.705	REPAIR PROCEDURE.
103E.711	COST APPORTIONMENT FOR JOINT COUNTY DRAINAGE SYSTEMS.
103E.715	REPAIR BY PETITION.
103E.721	REPLACEMENT AND HYDRAULIC CAPACITY OF BRIDGES AND CULVERTS.
103E.725	COST OF REPAIR.
103E.728	APPORTIONING REPAIR COSTS.
103E.729	APPORTIONING REPAIR COSTS; ALTERNATIVE OPTION.
103E.731	ASSESSMENT; BONDS.
103E.735	DRAINAGE SYSTEMS; REPAIR FUND.
103E.741	PROPERTY NOT ASSESSED BENEFITS; HEARING.
103E.745	COST OF REPAIR EXCEEDING BENEFITS IN ANOKA COUNTY.
CONSOLIDATING, DIVIDING, AND ABANDONING DRAINAGE SYSTEMS
103E.801	CONSOLIDATING OR DIVIDING DRAINAGE SYSTEMS.
103E.805	REMOVING PROPERTY FROM DRAINAGE SYSTEM.
103E.806	PARTIAL ABANDONMENT OF DRAINAGE SYSTEM.
103E.811	ABANDONING DRAINAGE SYSTEM.
103E.812	TRANSFER OF ALL OR PART OF DRAINAGE SYSTEM.