Skip to main content Skip to office menu Skip to footer
Capital IconMinnesota Legislature

Office of the Revisor of Statutes

    Subdivision 1. Definition. As used in this section, the term "public works contract" means a
contract of the state, or a county, city, town, school district, special district, or any other political
subdivision of the state, for the construction, alteration, repair, addition to, subtraction from,
improvement to, or maintenance of any building, structure, highway, bridge, viaduct, pipeline,
railway, public works, or any other works dealing with construction. The term includes, but
is not limited to, moving, demolition, or excavation performed in conjunction with the work
specified in this subdivision.
    Subd. 2. Unenforceability. Any clause in a public works contract that waives, releases,
or extinguishes the rights of a contractor to seek recovery for costs or damages, or seek an
equitable adjustment, for delays, disruption, or acceleration in performing the contract is void
and unenforceable if the delay, disruption, or acceleration is caused by acts of the contracting
public entity or persons acting on behalf of the public entity for which the public entity is
legally responsible.
    Subd. 3. Severability. When a contract contains a provision that is void and unenforceable
under subdivision 2, that provision must be severed from the other provisions of the contract to
the extent that it is void and unenforceable. The fact that the provision is void and unenforceable
does not affect the other provisions of the contract.
    Subd. 4. Scope and effect. Subdivision 2 does not make void and unenforceable any contract
provision of a public works contract that:
(1) requires notice of any delay, disruption, or acceleration by the party affected thereby;
(2) provides for reasonable liquidated damages; or
(3) provides for arbitration or any other procedure designed to settle contract disputes.
History: 2002 c 299 s 1

Official Publication of the State of Minnesota
Revisor of Statutes