2007 Minnesota Statutes
This is an historical version of this statute chapter. Also view the most recent published version.
103E.541 EXTENSION OF TIME ON CONTRACTS.
The auditors of affected counties may extend the time for the performance of a contract as
provided in this section. The contractor may apply, in writing, for an extension of the contract.
Notice of the application must be given to: (1) the engineer and the attorney for the petitioners;
and (2) for a joint county drainage project, to the auditors of the affected counties. The auditors
may grant an extension if sufficient reasons are shown. The extension does not affect a claim for
liquidated damages that may arise after the original time expires and before an extension or a
claim that may arise after the time for the extension expires.
History: 1990 c 391 art 5 s 73
The auditors of affected counties may extend the time for the performance of a contract as
provided in this section. The contractor may apply, in writing, for an extension of the contract.
Notice of the application must be given to: (1) the engineer and the attorney for the petitioners;
and (2) for a joint county drainage project, to the auditors of the affected counties. The auditors
may grant an extension if sufficient reasons are shown. The extension does not affect a claim for
liquidated damages that may arise after the original time expires and before an extension or a
claim that may arise after the time for the extension expires.
History: 1990 c 391 art 5 s 73
Official Publication of the State of Minnesota
Revisor of Statutes